Transform Your Bathroom Today

Effective Date: 1/1/25
Company: Bath Perfect, LLC ("Bath Perfect," "we," "our," or "us")

By accessing or using our services—including visiting our website at bathperfect.net, submitting inquiries, or hiring us for bathroom remodeling work—you agree to the following Terms of Service ("Terms").

Bath Perfect provides bathroom remodeling services, including consultations, design planning, demolition, installation, finishing, and subcontracted services as needed. The specific scope of your project will be detailed in a written proposal or service agreement.

All estimates provided are based on the information available at the time. Final costs may vary based on actual project conditions, material choices, and requested changes. Any significant changes will require written approval and may result in updated pricing and timelines.

You agree to:

• Provide accurate information about your project and home
• Give access to the project site as needed
• Communicate changes or concerns in a timely manner
• Pay invoices on time, per the agreed-upon terms 

Failure to meet these responsibilities may delay your project or result in additional charges.

Payment terms will be outlined in your proposal or invoice. Typically, we require:

• A deposit before work begins
• Progress payments based on milestones
• Final payment upon completion 

Late payments may be subject to fees or work stoppage until resolved. All payments are securely processed.

We make every effort to keep your project on schedule. However, delays may occur due to weather, supply chain issues, or subcontractor availability. We will communicate any changes promptly and work to resolve them as quickly as possible.

Bath Perfect may use qualified subcontractors to complete parts of your project. All subcontractors are carefully selected and expected to meet our quality standards.

We stand by our craftsmanship and offer a limited warranty on labor for [Insert warranty length, e.g., 1 year] from the project completion date. Warranty excludes:

• Normal wear and tear
• Customer-supplied materials
• Damage caused by misuse, neglect, or third parties
• Work modified by others after completion
   

If you choose to cancel your project after work has begun, you may be responsible for costs incurred to date, including labor, materials, and administrative fees. Refunds, if applicable, will be issued at our discretion based on the contract status.

All designs, photos, content, and materials shared by Bath Perfect (including those on our website) remain the intellectual property of Bath Perfect and may not be used or reproduced without written consent.

To the fullest extent permitted by law, Bath Perfect is not liable for indirect, incidental, or consequential damages arising from the use of our services. Our total liability is limited to the amount you paid us for the specific project or service in question.

These Terms are governed by the laws of the State of Utah. Any disputes will be resolved through arbitration or in the courts located in [Insert County], Utah.

We may update these Terms occasionally. Any updates will be posted on our website with a revised effective date. Continued use of our services constitutes acceptance of the updated Terms.

Bath Perfect, LLC
📍 Serving Utah
🌐 bathperfect.net
📧 info@bathperfect.sales@gmail.com
📞 801.726.5269